工期延误引起施工合同纠纷的解决

On solution of construction contract disputes by the construction period delay

工期的合理性直接影响工程质量和施工成本。工程情况的复杂多变难预料性,决定发包与承包双方签订合同的局限性和不完整性,合同工期延误在所难免。工期引起施工合同纠纷的焦点主要在工期顺延还是工期延误的判断和确认。文章通过工期延误引起施工合同纠纷的原因及分析,从发包与承包双方应共同确定好开工和竣工日期、创造良好开工条件、及时办理变更签证的角度提出解决方案,以利于工期延误产生施工合同纠纷的圆满解决,提高工程质量,保证工程经济效益。

The rationality of the time limit for a project directly influences the engineering quality and con- struction cost. The project itself is complicated and hard to predict, which results in the contract limitations and imperfection, and the delay of the project contract time is unavoidable. The focus of project contract dis- putes is extension of construction period or the judgement and confirmation of period delay.This article through the reason analysis for a project delay caused by construction contract disputes, from determining of opening and completion date, good conditions creating for launching and timely change with the visa, this article puts forward the solutions. It is good to solve the disputes,improve engineering quality, guarantee the engineering e- conomic benefits.