逾期违约金条款及其相关争议分析

Analysis of Liquidated Damage for Delay Clause and its Related Disputes

有关逾期违约金争议是较为常见的工程施工合同争议类型。本文以相关法律、司法解释、标准合同范本和法院相关判决为基础,对逾期违约金条款及其争议进行分析和讨论,并对承包商如何防范逾期违约金风险提出建议,以期对工程合同管理实务工作人员和相关工程专业人士更加深入理解工程施工合同中逾期违约金问题有所帮助。

The dispute of liquidated damage for delay(LAD)is not uncommon in construction and engineering. This paper demonstrates the typical and different types of LAD clauses and in-depth analysis of their disputes based on relevant law and judicial interpretation, clauses in the standard forms and judicial cases. It is concluded that following a list guidelines will greatly helpful for contractors effectively avoiding the risk of high LAD. And professionals in the field of construction management will increase understanding of LAD in construction contract from this study.